Quiero saber acerca de...

Federal Register / Vol. 86, No. 165 / Monday, August 30, 2021 / Notices SUPPLEMENTARY INFORMATION:

A. OMB control number, Title, and any Associated Forms 90000062, Certain Federal Acquisition Regulation Part 36
Construction Contract Requirements.

khammond on DSKJM1Z7X2PROD with NOTICES

B. Need and Uses This clearance covers the information that contractors must submit to comply with the following requirements in FAR
part 36:
FAR 52.2365, Material and Workmanship. This clause requires the contractor to obtain contracting officer approval of the machinery, equipment, material, or articles to be incorporated into the work. The contractors request must include: The manufacturers name, the model number, and other information concerning the performance, capacity, nature, and rating of the machinery and mechanical and other equipment; and full information concerning the material or articles. When directed by the contracting officer, the contractor must submit sufficient information on and, in some cases, samples of the items requiring approval. The contracting officer uses this information to determine whether the machinery, equipment, material, or articles meet the standards of quality specified in the contract. A contracting officer may reject work if the contractor installs machinery, equipment, material, or articles in the work without obtaining the contracting officers approval.
FAR 52.23613, Accident Prevention, Alternate I. This alternate to the basic clause requires the contractor to submit a written proposed plan to provide and maintain work environments and procedures that will safeguard the public and Government personnel, property, materials, supplies, and equipment exposed to contractor operations and activities; avoid interruptions of Government operations and delays in project completion dates;
and control costs in the performance of this contract. The plan must include an analysis of the significant hazards to life, limb, and property inherent in contract work performance and a plan for controlling these hazards. The contracting officer and technical representatives analyze the Accident Prevention Plan to determine if the proposed plan will satisfy the safety requirements identified in the contract, to include certain provisions of the Occupational Safety and Health Act and applicable standards issued by the Secretary of Labor at 29 CFR part 1926
and 29 CFR part 1910.

VerDate Sep<11>2014

18:40 Aug 27, 2021

Jkt 253001

FAR 52.23615, Schedules for Construction Contracts. This clause requires the contractor to prepare and submit to the contracting officer for approval three copies of a practicable schedule showing the order in which the contractor proposes to perform the work, and the dates on which the contractor contemplates starting and completing the several salient features of the work including acquiring materials, plant, and equipment. The contracting officer uses this information to monitor progress under a federal construction contract when other management approaches for ensuring adequate progress are not used.
C. Annual Burden Respondents: 4,412.
Total Annual Responses: 15,352.
Total Burden Hours: 12,034.
D. Public Comment A 60-day notice was published in the Federal Register at 86 FR 30936, on June 10, 2021. No comments were received.
Obtaining Copies: Requesters may obtain a copy of the information collection documents from the GSA
Regulatory Secretariat Division by calling 2025014755 or emailing GSARegSec@gsa.gov. Please cite OMB
Control No. 90000062, Certain Federal Acquisition Regulation Part 36
Construction Contract Requirements.
Janet Fry, Director, Federal Acquisition Policy Division, Office of Governmentwide Acquisition Policy, Office of Acquisition Policy, Office of Governmentwide Policy.
FR Doc. 202118622 Filed 82721; 8:45 am BILLING CODE 6820EPP

DEPARTMENT OF HEALTH AND
HUMAN SERVICES
Centers for Medicare & Medicaid Services CMS7064N

Announcement of the Advisory Panel on Outreach and Education APOE
September 15, 2021 Virtual Meeting Centers for Medicare &
Medicaid Services CMS, Health and Human Services HHS.
ACTION: Notice.
AGENCY:

This notice announces the next meeting of the APOE the Panel in accordance with the Federal Advisory Committee Act. The Panel advises and makes recommendations to the Secretary of the U.S. Department of
SUMMARY:

PO 00000

Frm 00041

Fmt 4703

Sfmt 4703

48425

Health and Human Services HHS the Secretary and the Administrator of the Centers for Medicare & Medicaid Services CMS on opportunities to enhance the effectiveness of consumer education strategies concerning the Health Insurance Marketplace, Medicare, Medicaid, and the Childrens Health Insurance Program CHIP. This meeting is open to the public.
DATES:

Meeting Date: Wednesday, September 15, 2021 from 12:00 p.m. to 5:00 p.m.
eastern daylight time e.d.t.
Deadline for Meeting Registration, Presentations, Special Accommodations, and Comments:
Wednesday, September 8, 2021, 5:00
p.m. e.d.t.
ADDRESSES:

Meeting Location: Virtual. All those who RSVP will receive the link to attend.
Presentations and Written Comments:
Presentations and written comments should be submitted to: Lisa Carr, Designated Federal Official DFO, Office of Communications, Centers for Medicare & Medicaid Services, 200
Independence Avenue SW, Mailstop 325G HHH, Washington, DC 20201, 2026905742, or via email at APOE@
cms.hhs.gov.
Registration: The meeting is open to the public, but attendance is limited to the space available. Persons wishing to attend this meeting must register at the website https www.eventbrite.com/e/
apoe-september-15-2021-virtualmeeting-tickets-151113822511 or by contacting the DFO listed in the FOR
FURTHER INFORMATION CONTACT section of this notice, by the date listed in the DATES section of this notice. Individuals requiring sign language interpretation or other special accommodations should contact the DFO at the address listed in the ADDRESSES section of this notice by the date listed in the DATES section of this notice.
Lisa Carr, Designated Federal Official, Office of Communications, 200 Independence Avenue SW, Mailstop 325G HHH, Washington, DC 20201, 2026905742, or via email at APOE@cms.hhs.gov.
Additional information about the APOE is available at: https
www.cms.gov/Regulations-andGuidance/Guidance/FACA/APOE. Press inquiries are handled through the CMS
Press Office at 202 6906145.

FOR FURTHER INFORMATION CONTACT:

SUPPLEMENTARY INFORMATION:

E:FRFM30AUN1.SGM

30AUN1